Terms of Service
Land Trade & Builders
Last Updated: June 2026
1. Agreement to Terms
By accessing and using the website of Land Trade & Builders (landtradeandbuilders.com), as well as any services, consultations, or property transactions offered by Land Trade & Builders, you agree to be bound by these Terms of Service.
If you do not agree to any part of these terms, you must not use our website or services.
2. Definitions
| Term | Definition |
|---|---|
| “Company” | Land Trade & Builders (Pvt) Ltd. |
| “Website” | landtradeandbuilders.com and all associated pages |
| “Services” | Property sales, design consultations, turnkey construction, verification services |
| “Consultation” | A meeting or call with our team to discuss property needs |
| “Property” | Any plot, house, or real estate offered by the Company |
| “User” | Any person accessing the website or using our services |
| “You” | The person or entity using our website or services |
3. Use License
3.1 What You Can Do
We grant you a limited, non-exclusive, non-transferable license to:
- Access and view the website
- Read blog articles and guides
- Browse property listings
- Request consultations
- Inquire about properties
3.2 Permitted Use
You agree to use the website only for:
- Lawful purposes
- Finding property information
- Requesting property viewings
- Contacting the Company
3.3 Prohibited Use
You agree NOT to:
- Scrape or extract data without permission
- Use the site for commercial purposes (resale, data mining)
- Post spam, viruses, or malware
- Harass or threaten other users or staff
- Impersonate anyone
- Copy content without permission
- Interfere with website functionality
- Violate any laws or regulations
- Upload illegal content
- Use automated tools (bots) to scrape data
- Attempt to hack or breach security
Violation may result in:
- Immediate suspension of access
- Legal action
- Damages recovered
4. Intellectual Property Rights
4.1 What We Own
All content on the website is owned or licensed by Land Trade & Builders:
- Text, articles, guides
- Images, photographs
- Logos, brand identity
- Design, layout, code
4.2 What You Can Use
You may:
- Download articles for personal use
- Share links to our website
- Reference our guides (with credit)
- Print content for personal reference
4.3 What You Cannot Do
You cannot:
- Copy blog articles and republish them elsewhere
- Use our logo or brand without permission
- Modify our content and represent it as yours
- Sell our guides or content
- Translate and republish without permission
Permitted exception: You may use small excerpts (1-2 paragraphs) with a link back to the original article.
4.4 User-Generated Content
If you submit content to us (photos, videos, testimonials):
- You grant us rights to use it for marketing
- You confirm you own the content
- You confirm you have the right to share it
- You indemnify us if there’s a copyright claim
5. Property Listings & Information
5.1 Accuracy of Listings
We strive to provide accurate property information, including:
- Pricing
- Location
- Features
- Size and specifications
However:
- Prices may change without notice
- Availability is subject to prior sale
- Images are for illustration (not guaranteed accurate)
- Property details should be verified in person
5.2 No Guarantee of Accuracy
Land Trade & Builders makes no warranty that:
- Property information is 100% accurate
- Prices are final
- Properties are available as shown
- Descriptions are complete
You agree to:
- Verify all information independently
- Conduct due diligence before buying
- Obtain independent legal/property verification
- Not rely solely on our website information
5.3 Property Verification
While we provide verification services, we do not guarantee:
- Absence of future disputes
- 100% legal clarity
- Complete absence of encumbrances
- Future market value
You are responsible for:
- Hiring independent lawyers
- Conducting independent surveys
- Obtaining independent title verification
- Making your own purchasing decisions
5.4 Reservation & Availability
If a property is listed, it is subject to:
- Prior sale (we may sell before you contact us)
- Withdrawal at any time
- Price changes
- Terms changes
No property is reserved until:
- A formal purchase agreement is signed
- An agreed deposit is paid
6. Consultation Services
6.1 What Consultations Include
Our free consultations typically cover:
- Discussion of your property needs
- Overview of available options
- General market information
- Timeline and process explanation
6.2 What Consultations Do NOT Include
Consultations are not:
- Legal advice (hire a lawyer for that)
- Tax advice (hire a tax consultant for that)
- Financial advice (hire a financial advisor for that)
- Guaranteed property sourcing
- Guaranteed purchase terms
6.3 Consultation Confidentiality
We keep your consultation information confidential, except:
- Sharing internally with team members who need to know
- Sharing with service providers (lawyers, architects) if you consent
- If required by law
6.4 No Obligation
Consultations create no obligation to:
- Buy from us
- Use our services
- Proceed with a transaction
- Sign any agreement
7. Purchase Transactions
7.1 No Purchase Obligations
Requesting information, taking a consultation, or viewing a property does NOT create any obligation to purchase.
7.2 Purchase Agreement
Any purchase must be formalized by:
- A written Purchase Agreement signed by both parties
- Specific terms regarding price, property, timeline
- Agreed conditions and contingencies
- Legal signatures (in person or notarized)
No verbal agreements, WhatsApp messages, or informal discussions constitute a binding contract.
7.3 Deposit & Payment Terms
Payment terms will be specified in the Purchase Agreement:
- Deposit amount and timeline
- Payment schedule
- Manner of payment (bank transfer, check, etc.)
- Conditions for deposit forfeiture
7.4 Financing & Mortgages
If you’re financing through a bank:
- You are responsible for securing mortgage approval
- We are not responsible for bank decisions
- Purchase may be contingent on mortgage approval
- Terms must be specified in writing
7.5 Due Diligence
You agree to conduct:
- Property verification (title, encumbrance, CDA status)
- Legal review by independent lawyer
- Physical inspection
- Neighbor interviews
- Tax/financial assessment
We recommend but do not require our verification services. You may hire independent verifiers.
8. Payment & Refunds
8.1 Accepted Payment Methods
- Bank transfer (SWIFT, IBEX)
- Check
- Cash (for smaller amounts, with receipt)
- Cryptocurrency (if agreed in writing)
8.2 Deposits
- Deposits are non-refundable unless otherwise agreed in writing
- If a property fails verification, deposit refund is negotiable
- If you withdraw without valid reason, deposit is forfeited
- Deposit amount will be specified in Purchase Agreement
8.3 Refund Policy
Refunds apply only if:
- Explicitly stated in Purchase Agreement
- Property verification reveals undisclosed issues
- Seller fails to deliver property
- Mutual agreement to cancel
Refunds typically take 7-14 business days after approval.
8.4 Currency
All prices are in Pakistani Rupees (PKR) unless otherwise stated. International buyers must arrange currency conversion.
9. Liability & Disclaimers
9.1 “As Is” Basis
The website and all information are provided “as is” without warranty. We disclaim:
- Merchantability
- Fitness for particular purpose
- Non-infringement
- Accuracy or completeness
9.2 Limitation of Liability
Land Trade & Builders is not liable for:
- Direct damages (property loss, financial loss)
- Indirect damages (lost profits, lost opportunity)
- Consequential damages
- Punitive damages
- Any damages arising from use of the website or services
Our total liability is limited to the amount paid by you to us (if any).
9.3 Third-Party Content
We are not responsible for:
- Content on linked websites
- Third-party services (payment processors, booking systems)
- Viruses or malware from external links
- Information from third-party sources
9.4 Property Disputes
If a property has a dispute (legal claim, ownership question):
- We are not liable for undisclosed disputes
- You are responsible for independent verification
- Claims must be raised before purchase completion
- Post-completion disputes are your responsibility
9.5 Market Risk
Property values fluctuate. We are not responsible for:
- Decline in property value
- Market corrections
- Economic downturns
- Your investment losses
10. Indemnification
You agree to indemnify and hold harmless Land Trade & Builders from:
- Claims arising from your use of the website
- Claims arising from your purchase of property
- Claims that you have violated any law
- Claims related to your information accuracy
- Disputes between you and other parties
11. Your Responsibilities
11.1 Information You Provide
You are responsible for:
- Accuracy of all information you provide
- Completeness of your details
- Legality of any information you submit
- Truthfulness in consultations and applications
11.2 Age & Capacity
You confirm:
- You are 18 years of age or older
- You have legal capacity to enter agreements
- You are not under any legal disability
11.3 Compliance with Laws
You agree to comply with:
- All applicable Pakistani laws
- All applicable laws in your country (if international)
- All immigration and tax laws
- All property purchase regulations
12. Website Terms
12.1 Availability
We aim to keep the website available 24/7, but:
- We may perform maintenance (sometimes with downtime)
- We may upgrade or modify the site
- We may temporarily restrict access for security
12.2 Website Interruptions
We are not liable for:
- Service interruptions
- Data loss due to technical issues
- Server downtime
- Security breaches (beyond our reasonable control)
12.3 Third-Party Links
Our website may link to:
- CDA website
- Government portals
- Payment processors
- Booking systems
- News sources
We are not responsible for their content or terms.
12.4 Cookies & Tracking
Our website uses:
- Cookies (session, preference, analytics)
- Google Analytics
- Facebook Pixel (retargeting)
- Third-party plugins
Read our Privacy Policy for details.
13. Confidentiality
13.1 Your Information
We keep your personal information confidential, except:
- As required by law
- With your explicit consent
- Sharing with staff who need to know
- Sharing with third-party service providers (lawyers, banks)
13.2 Our Information
You agree not to disclose:
- Pricing models
- Profit margins
- Proprietary processes
- Unreleased property listings
- Internal communications
13.3 Non-Disclosure
If you sign an NDA, it supersedes this clause.
14. Dispute Resolution
14.1 Governing Law
These Terms are governed by the laws of Pakistan and administered under Islamic Shariah principles where applicable.
14.2 Dispute Process
If a dispute arises:
Step 1: Good Faith Discussion (7 days)
- Contact us at: [contact@landtradeandbuilders.com]
- We’ll attempt to resolve within 7 days
Step 2: Mediation (14 days)
- If unresolved, we may suggest a neutral mediator
- Both parties agree to mediation costs
Step 3: Arbitration or Litigation
- If mediation fails, disputes proceed to:
- Arbitration (if agreed in writing), OR
- Pakistani courts (Islamabad District Courts)
14.3 No Class Action
You agree not to pursue class action lawsuits. Disputes must be handled individually.
14.4 Jurisdiction
You agree to the exclusive jurisdiction of Islamabad courts (or agreed arbitration).
15. Amendments & Changes
15.1 Right to Modify
We reserve the right to modify these Terms at any time:
- Changes take effect when posted
- Material changes will be announced
- Continued use means acceptance
15.2 Version Control
- Version 1.0: June 2026
- Previous versions available upon request
16. Termination of Access
16.1 We Can Terminate
We may suspend or terminate your access if:
- You violate these Terms
- You engage in illegal activity
- You post spam or malware
- You harass our staff
- You attempt to hack our website
- You use automated tools to scrape data
Termination is immediate without notice for serious violations.
16.2 Your Right to Terminate
You may stop using the website at any time. No termination notice required.
17. Specific Services Terms
17.1 Turnkey Construction
- Timeline: Subject to material availability and weather
- Price: Subject to material cost fluctuations
- Delays: May occur due to external factors
- Changes: Require written amendment to contract
- Quality: Per agreed specifications and Pakistan building codes
- Warranty: Typically 1 year on workmanship (details in construction agreement)
17.2 Plot Sales
- Title verification: By independent lawyer (recommended)
- Possession: Typically within 30-45 days of completion
- Development: No guarantee of society development timing
- Utilities: May take 6-12 months to be fully connected
- Appreciation: No guarantee of future value
17.3 Designer Homes
- Possession: Typically 3-6 months after agreement (custom homes)
- Design changes: May result in additional costs
- Delays: May occur due to construction issues
- Snagging: 15-30 days of minor fixes after handover
- Warranty: Per construction contract (typically 1 year)
18. Verification Services
18.1 What We Verify
If you use our verification services:
- CDA status and plot details
- Title deed authenticity
- Encumbrance certificate status
- Boundary survey results
- Ownership clarity
18.2 What We Don’t Guarantee
- Absence of future disputes
- Future legal challenges
- Complete accuracy of government records
- Absence of undisclosed claims
18.3 Verification Limitations
Verification is a single point in time snapshot. Claims may arise after verification.
19. WhatsApp Communications
19.1 WhatsApp Terms
When you message us on WhatsApp:
- You agree to WhatsApp’s Terms of Service
- You agree to our use of WhatsApp for business communication
- Message content may be stored for business records
19.2 Response Time
We aim to respond to WhatsApp messages within 24 hours. Urgent matters may require a phone call.
19.3 Confidentiality
WhatsApp messages are encrypted end-to-end, but:
- We store conversations on our device
- Messages are not completely private
- For sensitive matters, request an in-person meeting
20. Testimonials & Reviews
20.1 Your Permission
If you provide a testimonial or review:
- You grant us permission to publish it
- You confirm it’s truthful
- You confirm you own the opinion
- We may edit for clarity
20.2 Right to Remove
We reserve the right to remove any review that:
- Is defamatory
- Contains personal attacks
- Is spam or irrelevant
- Violates our policies
21. Limitation Period
Any legal claim against Land Trade & Builders must be filed within 1 year of the cause of action. Claims filed after 1 year are barred.
22. Severability
If any part of these Terms is found invalid, that part is severed, and the remaining Terms remain in effect.
23. Entire Agreement
These Terms, along with:
- Our Privacy Policy
- Your Purchase Agreement (if applicable)
- Any signed NDA
…constitute the entire agreement. Previous conversations or oral promises are not binding.
24. Contact Information
For questions about these Terms:
📧 Email: [info@landtradeandbuilders.com]
📱 WhatsApp: [Your WhatsApp number]
📞 Phone: [Your phone number]
🏢 Address: [Your office address in Islamabad]
We’ll respond within 5 business days.
25. Acknowledgment
By using Land Trade & Builders’ website or services, you acknowledge:
- You have read these Terms of Service
- You understand and accept all terms
- You have the capacity to be legally bound
- You will comply with all applicable laws
- You accept the risks associated with property purchase
- You will conduct independent verification
- You will hire independent legal counsel
26. Language
These Terms are provided in English. If translated to another language, the English version prevails in case of discrepancies.
27. Survival
The following sections survive termination of these Terms:
- Intellectual Property Rights
- Limitation of Liability
- Indemnification
- Dispute Resolution
- Governing Law
- Confidentiality
THANK YOU FOR USING LAND TRADE & BUILDERS.
We’re committed to transparent, honest real estate transactions.
Last Updated: June 2026
Version: 1.0
Quick Summary (Plain English)
We provide property services with these conditions:
✅ What you can do:
- Browse our website
- Request consultations
- View property listings
- Share links to our content
❌ What you can’t do:
- Copy our articles and republish
- Scrape our website
- Use our logo without permission
- Break the law
⚠️ Important:
- Verify property information independently
- Hire a lawyer before buying
- Don’t rely solely on our information
- We’re not liable for your decisions
💰 Payments:
- Deposits are typically non-refundable
- Prices in Pakistani Rupees
- Terms specified in purchase agreement
📋 Disputes:
- Try talking to us first
- Mediation if that fails
- Arbitration or Pakistani courts if needed
Questions? Contact us at [contact@landtradeandbuilders.com]
These Terms are legally binding. By using our website or services, you accept them.